Fdrationnternationaledesingnieurs-conseilsInternationalFederationofconsultingEngineersinternationalevereinigungBeratenderngenieureFederaciinnternacionaldeIngenierosconsuitores

Amendmentstothe

FIDICConditionsofContract

FORFOR

DESIGNEDSECOND

PLANTANDDESIGN-BUILD

ELECTRICAL&MECHANICALPLANT,ANDFORBUILDINGAND

ENGINEERINGWORKS,

BYTHECONTRACTOR,EDITION2017

ISBN978-2-88432-082-5

AmendmentstotheFIDICConditionsofContractforPlantandDesign-Buildfor

Electrical&MechanicalPlant,andforBuildingandEngineeringWorks,designedbythe

Contractor,SecondEdition2017[ISBN978-2-88432-082-5]

Followingpublicationin2017oftheSecondEditionoftheConditionsofContractforPlantandDesign-Build[ISBN978-2-88432-082-5],anumberofamendmentswereagreedbyFIDIC.FIDICpublishedthefirstsetofamendmentsasanerratadocumentinDecember2018.ThiswasfollowedbyasecondsetofamendmentsofadditionalerrataintheformofamemorandumpublishedinJune2019.Sincethen,FIDIChasidentifiedfurtheramendmentstoimprovethesaidpublication.FIDICisherebypublishingathirdsetofamendmentsinNovember2022effectiveasof1January2023.

Theabovethreesetofamendmentsareprovidedbelowasthreeseparatedocuments.Inaddition,severalminortypographicalerrorsandlayoutirregularitiesthathavealsobeencorrectedinthe2017publicationarenotlistedbelow.

PagenumbersandlinesgivenbelowarereferencestopagesnumbersandlinesintheFIDICConditionsofContractforPlantandDesign-Build,SecondEdition2017,[ISBN978-2-88432-082-5].

AmendmentsIssueNo.1–December2018

ErratatotheFIDICConditionsofContractforPlantandDesign-Build,SecondEdition2017[ISBN978-2-88432-082-5]

ThefollowingsignificanterrataarenotincludedinthecontentoftheSecondEditionoftheConditionsofContractforPlantandDesign-Build.Severalminortypographicalerrorsandlayoutirregularitieshavealsobeenfoundbutarenotincludedinthislistduetotheirinsignificancewithregardtothecontent.

GENERALCONDITIONS

Page5Sub-Clause1.1.48:Onthesecondline,replace“Specification”with“Employer’sRequirements”.

Page7Sub-Clause1.1.79:Onthesecondlineafter“PaymentCertificateunder”,add“Sub-Clause

14.2.1[AdvancePaymentGuarantee](ifapplicable),”.

Page7Sub-Clause1.1.84:Onthesecondline,replace“Specification”with“Employer’sRequirements”.

Page7Sub-Clause1.1.88:Onthefirstline,replace“anychangetotheWorks”with“anychangetothe

Employer’sRequirementsortheWorks”.

Page27Sub-Clause4.5.1:Insub-paragraph(a)onthefirstlinebefore“Subcontractor”,add“nominated”.

Page28Sub-Clause4.6:Onthesecond-lastlineofthefirstparagraphbefore“Contractor’s”,add“of

the”.

Page37Sub-Clause4.22:Onthethirdlineofthesecondparagraphbefore“4.17”,add“Sub-Clause”.

Page42Sub-Clause6.1:Onthefirstline,replace“Specification”with“Employer’sRequirements”.

Page64Sub-Clause12.1:Insub-paragraph(b)(ii)onthesecondline,delete“been”.

Page71Sub-Clause13.6:Inthefourthparagraph:

-attheendofsub-paragraph(ii),delete“(withdetailedsupportingparticulars)”;

-attheendofthisfourthparagraph,add“(withdetailedsupportingparticulars)”.

Page73Sub-Clause14.2.1:Onthefifthandsixthlinesofthefirstparagraph,replace“basedonthe

sampleformincludedintheTenderdocuments”with“intheformannexedtotheParticularConditions”.

Page81Sub-Clause14.12:Ontheseventhlineofthefirstparagraph,replace“Sub-Clause21.6

[Arbitration]”with“Clause21[DisputesandArbitration]”.

?FIDIC20221

Page90Sub-Clause17.1:Onthefourthandfifthlinesofthefirstparagraph,replace“DateofCompletion

oftheWorks”with“issueoftheTaking-OverCertificatefortheWorks”.

Page91Sub-Clause17.3:Onthefirstlineofthesecondparagraph,replace“notice”with“aNotice”.

Page97Sub-Clause19.2.3:Onthefirstlineofthefirstparagraph,replace“thepartofthePermanent

WorksunderSub-Clause4.1[Contractor’sGeneralObligations],and/oranyotherdesignundertheContract”with“thePermanentWorks”.

APPENDIX–GENERALCONDITIONSOFDISPUTEAVOIDANCE/ADJUDICATIONAGREEMENT

Page110TitleReplace“GeneralConditionsofDisputeAvoidance/AdjudicationAgreement”

with“GeneralConditionsofDAABAgreement”.

Page110Sub-Clause1.2:Onboththefirstandthirdlines,replace“DAAAgreement”with“DAAB

Agreement”.

Page110Sub-Clause1.3:-onthefirstline,replace““DisputeAvoidance/AdjudicationAgreement”

or“DAAAgreement”means”with:

““DAABAgreement”isasdefinedundertheContractandis”;

-onthefirstlineofsub-paragraph(c),replace“DAAAgreement”with“DAABAgreement”;

Pages110to119

Sub-Clause1.7toClause12:

-insub-paragraph(c)(ii),replace“chairman”with“chairperson”.Replaceallinstancesof“DAAAgreement”with“DAABAgreement”.

Page118Sub-Clause11.1:Onthesecondline,deletethetext:

“,orinthecaseofathree-memberDAABtheOtherMembersjointly,”.

ANNEX–DAABPROCEDURALRULES

Page121Rule4.2Onthefourthline,replace“chairman”with“chairperson”.

Page124Rule8.3Onthesixthline,replace“chairman”with“chairperson”.

GUIDANCEFORTHEPREPARATIONOFPARTICULARCONDITIONS

Page8INTRODUCTIONInsertinthebeginningofGP5:“Unlessthereisaconflictwiththegoverning

lawoftheContract,…”allowingGP5toread:

“GP5:UnlessthereisaconflictwiththegoverninglawoftheContract,allformaldisputesmustbereferredtoaDisputeAvoidance/AdjudicationBoard(oraDisputeAdjudicationBoard,ifapplicable)foraprovisionallybindingdecisionasaconditionprecedenttoarbitration.”.

PagesGuidanceforReplaceallinstancesof“SampleForms”with“Forms”.

15to51Sub-Clauses1.6,1.14,4.2,14.2,14.9,14.15and21.1

FormofLETTEROFACCEPTANCE

PageiiFootnoteReplace“1.1.51”with“1.1.50”.

FormofDISPUTEAVOIDANCE/ADJUDICATIONAGREEMENT

PagesivandvReplaceallinstancesof“DAAAgreement”with“DAABAgreement”.

PageivRecitalCOnthefirstlineofsub-paragraph(b),replace“chairman”with“chairperson”.

?FIDIC20222

(d)theEmployerfailstocomplywith:

theContractormay,notlessthan21daysaftergivingaNoticetothe...

AmendmentsIssueNo.2–June2019

ErratatotheFIDICConditionsofContractforPlantandDesign-BuildSecondEdition2017[ISBN978-2-88432-082-5]

GENERALCONDITIONS

Page87Sub-Clause16.1:

Thesentence“andsuchfailureconstitutesamaterialbreachoftheEmployer’sobligationsundertheContract”followingsub-paragraph(d)shouldbeindentedsoastobeclearthatitispartofsubparagraph(d).

(i)abindingagreement,or?nalandbindingdeterminationunderSub-Clause3.7[AgreementorDetermination];or

(whetherbindingor?nalandbinding)

(ii)adecisionoftheDAABunder21.4[ObtainingDAAB’sDecision]

andsuchfailureconstitutesamaterialbreachoftheEmployer’sobligationsundertheContract,

AmendmentsIssueNo.3–November2022

AmendmentstotheFIDICConditionsofContractforPlantandDesign-BuildSecondEdition2017

[ISBN978-2-88432-082-5]

ThefollowingamendmentsaremadetotheFIDICConditionsofContractforPlantandDesign-Build,SecondEdition,2017,effectiveasof1January2023.

Coverpage:Inthetextunderthemaintitle,replace“DisputeAdjudication/Avoidance

Agreement”with“DAABAgreement”.

GENERALCONDITIONS

Titlepage1:Ontheright-handside,replace“DisputeAdjudication/AvoidanceAgreement”

with“DAABAgreement”.

Page1Sub-Clause1.1.5:Onthefirstlineafter“totheotherParty”,add“(excludingamattertobeagreed

ordeterminedundersub-paragraph(a)ofSub-Clause3.7[AgreementorDetermination])”.

Page1Sub-Clause1.1.8:Onthesecondlinereplace“asamendedby”with“and”.

Page2Sub-Clause1.1.23:Onthefifth/sixthlinereplace“DisputeAvoidance/AdjudicationAgreement”

with“DAABAgreement”.

Page2,3Sub-Clause1.1.24:Onthesecondline,after“theEngineer”,add“underSub-Clause10.1

[TakingOvertheWorksandSections]orthefirstparagraphofSub-Clause

10.2[TakingOverParts]”.

Onthefourthandfifthlines,replace“ifSub-Clause10.2[TakingOverParts]”with“ifthesecondparagraphofSub-Clause10.2[TakingOverParts]”.

?FIDIC20223

Page3Sub-Clause1.1.29:Replacethetextofthisdefinitionwith:

““Dispute”meansanysituationwhere:

“(a)onePartyhasmadeaClaim,ortherehasbeenamattertobeagreedordeterminedundersub-paragraph(a)ofSub-Clause3.7[AgreementorDetermination];

(b)theEngineer’sdeterminationunderSub-Clause3.7.2[Engineer’sDetermination]wasarejection(inwholeorinpart)of:

(i)theClaim(ortherewasadeemedrejectionundersub-paragraph

(i)ofSub-Clause3.7.3[Timelimits]);or

(ii)aParty’sassertion(s)inrespectofthematterasthecasemaybe;and

(c)eitherPartyhasgivenaNODunderSub-Clause3.7.5[DissatisfactionwithEngineer’sdetermination].”.

Page4Sub-Clause1.1.37:Onthefirstlineofthefirstparagraphadd“exceptional”before“eventor

circumstance”.

Page4Sub-Clause1.1.43:Replacethetextofthisdefinitionwith:

““GeneralConditions”meansthisdocumententitled“GeneralConditions”,aspublishedbyFIDIC.”.

Page5Sub-Clause1.1.58:Replacealltextafter“whichis”onthesecondlinebythefollowing:“taken

overbytheEmployerunderthefirstparagraph,orusedbytheEmployeranddeemedtohavebeentakenoverunderthesecondparagraph,ofSub-Clause10.2[Taking-OverParts].”.

Page7Sub-Clause1.1.84:Onthesecond/thirdlinesreplace“inaccordancewiththeSpecialProvisions”

with“underClause12[TestsafterCompletion]”.

Page8Sub-Clause1.3:Onthefifthlineofthefirstparagraph,before“discharge,”,add“disagreement,”.

Page9,10Sub-Clause1.5:Onthesecondlineofthefirstparagraph,after“Ifthereisanyconflict,

ambiguityordiscrepancy”andbeforethecomma,add:“inthedocuments”.

Onthefirstlineofthelastparagraph,replace“anambiguity”with“aconflict,ambiguity”.

Onthesecondlineofthelastparagraph,replace“theambiguity”with“theconflict,ambiguity”.

Onthethirdlineofthelastparagraph,replace“anambiguity”with“aconflict,ambiguity”.

Page11Sub-Clause1.9:Onthefirstandsecondlinesofthelastparagraphreplace“If,under

sub-paragraph(b)above,anexperiencedcontractorwouldnothavediscoveredtheerror,faultorotherdefect:”with:

“Ifitisagreedordetermined,undersub-paragraphs(a)and(b)above,thatthereisanerror,faultordefectthatanexperiencedcontractorwouldnothavediscovered:”.

Onthefirstlineofsub-paragraph(ii),replace“iftheContractor”with“iftherearenosuchmeasures,andthereforenoVariation,buttheContractor”.

Page14Sub-Clause1.15:Inthesecondparagraphattheendofthefirstsentenceadd“under”after

“otherthan”anddelete“under”insub-paragraphs(i)to(iv).

Page17Sub-Clause3.1:Insub-paragraph(b)delete“shallbe”.

Page18Sub-Clause3.4:Onthesecond-lastlineofthelastparagraph,after“receivingtheContractor’s

Notice,”add“bygivingaNotice”.

Page19Sub-Clause3.6:Onthesecondlineofthelastparagraphreplace“anentity”with“alegal

entity”.

?FIDIC20224

Page20Sub-Clause3.7:Replacethesecondparagraphwith:

“WhenevertheseConditionsprovidethattheEngineershallproceedunderthisSub-Clause3.7toagreeordetermineeither:

(a)anymatter,asprovidedforinSub-Clauses1.9,4.7.3,10.2,11.2,13.3.1,13.5,14.4,14.5,14.6.3,15.3,15.6and18.5,identifyinginthesameSub-ClausethedateofcommencementofthecorrespondingtimelimitforagreementunderSub-Clause3.7.3[Timelimits];or

(b)anyClaim,

thefollowingprocedureshallapply:”.

Page20,21Sub-Clause3.7.3:Onthefirstlineofsub-paragraph(a)replace“(notaClaim)”with“under

sub-paragraph(a)ofSub-Clause3.7[AgreementorDetermination]”.Onthefirstlineofthelastparagraph,delete“agreementor”.

Onthefirstlineofsub-paragraph(ii)ofthelastparagraphafter“mattertobeagreedordetermined”add“undersub-paragraph(a)ofSub-Clause3.7[AgreementorDetermination]”.

Page24Sub-Clause4.2.1:Onthethirdlineofthelastparagraph,after“increaseordecreaseofthe

ContractPrice”,add“inonecurrency”.

Onthelastlineofthelastparagraph,after“AcceptedContractAmount”,add“inthatcurrency”.

Page26Sub-Clause4.4:Onthesecondlineofthesecond-lastparagraphafter“theContractorshall

submit”,add“totheEngineer”.

Onthefourthlineofthesecond-lastparagraph,delete“totheEngineer”.

Page29Sub-Clause4.7.3:Onthefirstandsecondlinesofthelastparagraphreplace“If,under

sub-paragraph(b)above,anexperiencedcontractorwouldnothavediscoveredtheerror:”with:

“Ifitisagreedordetermined,undersub-paragraphs(a)and(b)above,thatthereisanerrorintheitemsofreferencethatanexperiencedcontractorwouldnothavediscovered:”.

Onthefirstlineofsub-paragraph(ii),replace“iftheContractor”with“iftherearenosuchmeasures,andthereforenoVariation,buttheContractor”.

Page50Sub-Clause8.3:Onthefirstandsecondlinesofthelastparagraph,replace“theProgramme”

with“anyprogramme”.

Page51Sub-Clause8.5:Replacethesecond-lastparagraphwith“Whenagreeingordetermining

eachEOT,theEngineershallreviewpreviousagreementsanddeterminationsofEOTunderSub-Clause3.7[AgreementorDetermination]andmayincrease,butshallnotdecrease,thetotalEOT.”.

Page56Sub-Clause9.4:Onthefirstlineofsub-paragraph(a),replace“order”with“instruct”.

Page57Sub-Clause10.1:Onthethirdlineofsub-paragraph(b),after“sub-paragraph(a)”,add“or

sub-paragraph(b)(i)(asthecasemaybe)”.

Onthesecondlineofsub-paragraph(c),replace“provisional”with“final”.

Onthefirstlineofthethirdparagraph,replace“PartoftheWorksistakenover”with“Partistakenoverorisdeemedtohavebeentakenover”.

Page58Sub-Clause10.2:Onthefirstlineofthethirdparagraph,replace“theEngineerhasissueda

Taking-OverCertificateforaPart”with“aParthasbeentakenoverorisdeemedtohavebeentakenover”.

Onthefirstandsecondlinesofthefourthparagraph,replace“theEmployertakingoverand/orusingaPart”with“thetakingoverordeemedtakingoverofaPart”.

?FIDIC20225

Inthelastparagraph:

-replacethefirstsentencewiththefollowing:“ForanyperiodofdelayafterthedatethataParthasbeentakenoverorisdeemedtohavebeentakenover,theDelayDamagesforcompletionoftheWorksortheSection(asthecasemaybe)inwhichthisPartisincludedshallbereduced.”;

-deletethesecondsentence:“Similarly,theDelayDamagesfortheremainderoftheSection(ifany)inwhichthisPartisincludedshallalsobereduced.”;

-replacethefourthsentencewiththefollowing:“TheEngineershallproceedunderSub-Clause3.7[AgreementorDetermination]toagreeordeterminethisreduction(and,forthepurposeofSub-Clause3.7.3[Timelimits],thedatetheEngineerissuestheTaking-OverCertificateunderthefirstparagraphof,orreceivestheContractor’sNoticeunderthesecondparagraphof,thisSub-Clause(asthecasemaybe)shallbethedateofcommencementofthetimelimitforagreementunderSub-Clause3.7.3).”.

Page59Sub-Clause10.4:Onthesecondline,replace“PartoftheWorks”with“Part”.

Page60Sub-Clause11.3:Onthefourthlineofsub-paragraph(a),replace“matters”with“causes”.

Page79Sub-Clause14.9:Insub-paragraph(b),delete“for”.

Onthefirstlineofthethirdparagraph,after“IPC”,add“,ortheFPC(asthecasemaybe),”.

Page82Sub-Clause14.13:Replacethelastparagraphwith“IftheContractorhasnotsubmitteda

dischargeunderSub-Clause14.12[Discharge]buthaseither:

(i)submittedaPartiallyAgreedFinalStatementunderSub-Clause14.11.2[AgreedFinalStatement];or

(ii)notdonesobut,totheextentthatadraftfinalStatementsubmittedbytheContractorisdeemedbytheEngineertobeaPartiallyAgreedFinalStatement,

theEngineershallproceedinaccordancewithSub-Clause14.6[IssueofIPC]toissueanIPC.”.

Page85Sub-Clause15.2.3:Onthesecondlineofsub-paragraph(a),replace“thisSub-Clause”with

“Sub-Clause15.2.2[Termination]”.

Page90Sub-Clause17.1:Onthefifthlineofthefirstparagraph,after“theissue”add“(ordeemed

issue)”.

Page91Sub-Clause17.2:Replacethetextofsub-paragraph(e)initsentiretywith“anyExceptional

Event;and/or”.

Insub-paragraph(f),after“anyactordefaultof”add“theEmployer,”.Inthesecond-lastparagraph:

-onthefirstline,replace“SubjecttoSub-Clause18.4[ConsequencesofanExceptionalEvent],if”with“If”.

-onthethirdline,replace“damage”with“l(fā)ossand/ordamage”.

-onthelastlineafter“[VariationbyInstruction]”,add:“and,inthecaseofsub-paragraph(e)above,shallbewithoutprejudicetoanyotherrightstheContractormayhaveunderSub-Clause18.4.[ConsequencesofanExceptionalEvent]”.

Inthelastparagraph:

-onthefirstline,replace“l(fā)ossordamage”with“l(fā)ossand/ordamage”.

-onthelastline,replace“delays”with“delay”.

?FIDIC20226

Page93Sub-Clause18.1:Onthefirstlinebefore“event”add“exceptional”.

Page99Sub-Clause20.1:Onthefourthlineofsub-paragraph(c),delete“determination”.

Onthefourthlineofthelastparagraphreplace“butthe”with“exceptifanyofsub-paragraphs(a)to(c)ofSub-Clause21.4[ObtainingDAAB’sDecision]applies.The”.

Page100Sub-Clause20.2.2:Onthefourthlineofthelastparagraphreplace“[Fullydetailedclaim]”with

“[FullydetailedClaim]”.

Page101Sub-Clause20.2.4:Onthefourthlineofthesecond-lastparagraphreplace“fullydetailedclaim

shallinclude”with“fullydetailedClaimshallbesupplementedwith”.

Page101Sub-Clause20.2.5:Onthesixthlineofthesecondparagraphreplace“fullydetailedclaim”with

“fullydetailedClaim”.

Page105Sub-Clause21.2:Attheendofsub-paragraph(d)after“todoso,”add:

“,orbecausethetermsoftheDAABAgreement(includingtheamountofthemonthlyfeeorthedailyfee)cannotbeagreedwiththememberorreplacementwithin14daysafterhe/shehasbeenadvisedbythePartiesthattheyhaveagreedtohis/herappointment,”.

Inthefirstparagraphdeletethetextthatfollowssub-paragraph(d)andreplacewiththefollowing:

“then,unlessotherwiseagreedbytheParties,eitherorbothPartiesmayapplytothePresidentofFIDICorapersonappointedbythePresident,whoshallbetheappointingofficialundertheContract.Theappointingofficialshall,afterdueconsultationwithbothPartiesandafterconsultingtheprospectivemember(s)orreplacement:

-appointthemember(s)oftheDAABorthereplacement;and

-setthetermsoftheappointment,includingtheamountsofthemonthlyfeeandthedailyfeeforeachmemberorreplacement.

Selectionofthemember(s)orreplacementtobesoappointedshallnotbelimitedtothosepersonsnamedinthelistintheContractDataor,inthecaseofsub-paragraph(d)above,tothemember(s)orreplacementagreedbytheParties.

Thisappointmentanditstermsshallbefinalandconclusive.”.Onthesecondlineofthelastparagraph,delete“entityor”.

Page105Sub-Clause21.4:Onthethirdandfourthlinesreplace“andthefollowingprovisionsshallapply”

withafullstop“.”,andaddthefollowingtextasnewparagraphs:

“InadditiontothesituationdescribedinthedefinitionofDisputeunderSub-Clause1.1.29above,aDisputeshallbedeemedtohavearisenif:

(a)thereisafailureasreferredtoundersub-paragraph(b),oranon-paymentasreferredtoundersub-paragraph(c),ofSub-Clause16.2.1[Notice];

(b)theContractorisentitledtoreceivefinancingchargesunderSub-Clause

14.8[DelayedPayment]butdoesnotreceivepaymentthereoffromtheEmployerwithin28daysafterhisrequestforsuchpayment;or

(c)aPartyhasgiven:

(i)aNoticeofintentiontoterminatetheContractunderSub-Clause

15.2.1[Notice]orSub-Clause16.2.1[Notice](asthecasemaybe);or

(ii)aNoticeofterminationunderSub-Clause15.2.2[Termination],Sub-Clause16.2.2[Termination],Sub-Clause18.5[OptionalTermination]orSub-Clause18.6[ReleasefromPerformanceundertheLaw](asthecasemaybe);

?FIDIC20227

andtheotherPartyhasdisagreedwiththefirstParty’sentitlementtogivesuchNotice;

whichDisputemaybereferredbyeitherPartyunderthisSub-Clause21.4withouttheneedforaNOD(andSub-Clause3.7[AgreementorDetermination]andsub-paragraph(a)ofSub-Clause21.4.1[ReferenceofaDisputetotheDAAB]shallnotapply).

WhereaDisputeistobereferredtotheDAABforitsdecision,thefollowingprovisionsshallapply.”.

Page106Sub-Clause21.4.1:Insub-paragraph(a)replace“ifSub-Clause3.7[AgreementorDetermination]

appliedtothesubjectmatteroftheDispute”with“subjecttosub-paragraph(ii)ofSub-Clause3.7.3[Timelimits]andtheprovisionsofthesecondparagraphofSub-Clause21.4[ObtainingDAAB’sDecision]”.

APPENDIX–GENERALCONDITIONSOFDAABAGREEMENT

Page110

Clause1:

ReplacetheSub-Clausenumberingforthelastfivedefinitionswith“1.4”to“1.8”,respectively.

Page110

Sub-Clause1.1:

Replace“GeneralConditionsofDisputeAvoidance/AdjudicationAgreement”,inthetwoinstances,with“GeneralConditionsofDAABAgreement”.

Page112

Sub-Clause4.1:

Replacesub-paragraph(c)withthefollowing:

“(c)inthe5yearsbeforesigningtheDAABAgreement,nothavebeenemployedasaconsultantorotherwisebytheEmployer,theContractor,theEmployer’sPersonnelortheContractor’sPersonnel,exceptinsuchcircumstancesasweredisclosedinwritingtotheEmployerandtheContractorbeforetheysignedtheDAABAgreement(oraredeemedtohavedoneso);”.

Page115

Sub-Clause9.1:

Replacesub-paragraphs(b)(iv)and(b)(v)intheirentiretywiththefollowing:“(iv)spentonpreparingandattendinghearings(and,incaseofa three-memberDAAB,attendingmeeting(s)betweentheDAABMembersinaccordancewithsub-paragraph(a)ofRule8.2oftheDAABRules,

andcommunicatingwiththeOtherMembers);and

(v)spentonpreparingdecisions,includingstudyingwrittendocumentationandargumentsfromtheParties.”.

Insub-paragraph(c),replace“telephonecalls(andvideoconferencecalls,ifany,andinternetaccess)”with“internetaccess”.

Page115

Sub-Clause9.2:

Onthesecond-lastandlastlines,delete“(or,undertheContract,deemedtohavebeensigned)”.

Page115

Sub-Clause9.3:

ReplacethetextofthisSub-Clauseinitsentiretywith:

“IftheDAABMemberhasbeenappointedbytheappointingofficial,theamountsoftheDAABMember’smonthlyfeeanddailyfee,underSub-Clause9.1above,shallbeasreferredtoundersub-paragraph(i)ofSub-Clause

21.2[FailuretoAppointDAABMember(s)]oftheConditionsofContract.”.

Page116

Sub-Clause9.6:

Inthefirstparagraphreplacethenumberingofthethirdsub-paragraphfrom“b”to“c”.

Page116

Sub-Clause9.7:

Insub-paragraph(b),before“resign”,add“withoutprejudicetohis/herotherrightsorremedies,”.

Page117

Sub-Clause10.2:

Onthefourthline,replace“notice”with“Notification”.

Page118

Sub-Clause11.1:

Onthefourthline,delete“ObjectionProcedure”.

Onthefourthandfifthlines,delete“ChallengeProcedure”.

Page119

Clause12:

Delete“2017”,delete“andArticle30”,anddelete“atAppendixVI”.

?FIDIC2022