版權(quán)說明:本文檔由用戶提供并上傳,收益歸屬內(nèi)容提供方,若內(nèi)容存在侵權(quán),請進行舉報或認領(lǐng)
文檔簡介
2025年船舶建造合同英文版范本解讀ThisStandardContractforShipConstruction(the"Contract")isenteredintoasof[InsertDate],byandbetween[Shipowner'sFullLegalName]("Shipowner"),havingitsprincipalplaceofbusinessat[Shipowner'sAddress],and[Shipbuilder'sFullLegalName]("Shipbuilder"),havingitsprincipalplaceofbusinessat[Shipbuilder'sAddress].1.DefinitionsandInterpretationInthisContract,unlessthecontextotherwiserequires:1.1"Vessel"meansthe[SpecifyVesselType,e.g.,ContainerShip]tobeconstructedunderthisContract,tobeknownas[SpecifyVesselName,ifknown],andhavingthespecificationssetforthinScheduleAattachedheretoasanexhibit.1.2"Contract"meansthisContracttogetherwithallschedules,exhibits,andamendmentstheretowhichmaybeexecutedbythePartiesfromtimetotime.1.3"Completion"meansthestateinwhichtheVesselhasbeenconstructedinaccordancewiththeSpecifications,hassuccessfullycompletedtheSeaTrialasdefinedherein,andtheShipbuilderhasobtainedtherelevantclasscertificatefortheVesselfrom[NameofClassificationSociety].1.4"Lay-downDate"means[InsertDateorDescriptionofEventTriggeringLay-down].1.5"DeliveryDate"meansthedateonwhichtheVesselisdeliveredtotheShipownerattheDeliveryPointasspecifiedinClause4.3.1.6"Specifications"meansthetechnicalspecifications,drawings,calculations,andotherdocumentsdefiningtheVessel'sdesign,equipment,andperformancerequirementssetforthinScheduleA.1.7"ScheduleA"referstotheScheduleofSpecificationsattachedheretoasanexhibit.1.8"WorkingDay"meansanydayotherthanaSaturday,Sunday,orpublicholidayapplicabletothePartiesattheplacewheretherelevantworkisbeingperformed.1.9"GoverningLaw"means[SpecifyJurisdiction,e.g.,thelawsoftheUnitedKingdom]asamendedfromtimetotime.1.10"Arbitration"meansthedisputeresolutionprocedureconductedundertheRulesof[SpecifyArbitrationInstitution,e.g.,theLondonMaritimeArbitratorsAssociation]asinforceatthedateofinstitution.2.Construction2.1TheShipbuildershallconstructtheVesselinaccordancewiththeSpecificationssetforthinScheduleA.2.2TheShipbuildershallprovideaWorkProgrammedetailingtheintendedconstructionschedule,subjecttothetermsofthisContract.TheShipownershallreviewtheWorkProgrammeandshallnotbeliableforanydelayscausedbyapprovedvariationstotheWorkProgramme.2.3TheShipbuildershallbearallcostsandrisksassociatedwiththedesignandconstructionoftheVessel,unlessotherwisespecifiedinthisContract.3.InspectionandSurvey3.1TheShipbuildershallberesponsibleforallinspectionandsurveycostsincurredduringtheconstructionperiod,exceptforthesurveysrequiredbytheClassificationSocietyandagreedinadvance.3.2TheClassificationSocietyshallconductinspectionsandsurveysatitsownexpenseattheShipbuilder'ssite.TheresultsoftheseinspectionsandsurveysshallbedeemedsatisfactoryunlessnotifiedinwritingbytheClassificationSocietywithin[Number,e.g.,14]daysofthesurvey.TheShipbuildershallcorrectanydeficiencieswithinareasonabletimeasdirectedbytheClassificationSociety.3.3TheShipownershallhavetherighttoappointitsownrepresentativestoinspectandsurveytheVesselatanystageofconstruction.TheShipbuildershallprovidereasonableaccessandcooperation,butshallnotbeliableforanydelaysorcostsincurredbytheShipowner'srepresentatives.3.4AllinspectionreportsshallbesubmittedtotheotherPartywithin[Number,e.g.,10]daysofcompletionoftheinspection.Disagreementsarisingfrominspectionreportsshallberesolvedthroughnegotiation.Ifunresolved,themattermaybesubmittedtotheArbitration.4.Delivery4.1TheDeliveryPointshallbe[SpecifyDeliveryPoint,e.g.,theShipbuilder'syardatPortX].4.2TheVesselshallbedeemeddeliveredtotheShipownerwhenitisreadyfordelivery,locatedattheDeliveryPoint,andtheShipbuilderhasgivenwrittennoticeofreadinesstotheShipowner.4.3TheShipownershallberesponsibleforallcostsandrisksoftheVesselfromthemomentofdeliveryunderthisClause4.2.4.4TitletotheVesselshallpasstotheShipownerupontheearlierof:(a)thedateofDeliveryasdefinedinClause4.2;and(b)thefullpaymentbytheShipownertotheShipbuilderunderthisContract.5.ContractPriceandPayment5.1TheContractPricefortheVesselis[SpecifyAmountinWordsandFigures]([SpecifyCurrency,e.g.,USD])(the"ContractPrice").5.2TheContractPriceshallbesubjecttoanescalationclausebasedonthe[SpecifyIndex,e.g.,PlattsHotRollingPlateIndexforChina]publishedby[SpecifyPublisher]onthe[SpecifyDay,e.g.,firstbusinessday]ofeachmonthduringtheconstructionperiod,withadjustmentseffectivefromthebeginningofthemonthfollowingthepublicationdateoftheindex.TheescalationshallbecalculatedbytheShipbuilderandconfirmedinwritingtotheShipownerwithin[Number,e.g.,30]daysoftheendofeachmonth.Theadjustmentshallbesubjecttomutualagreement;ifnotagreedwithin[Number,e.g.,60]days,themattershallbesubmittedtotheArbitration.5.3TheShipownershallpaytheContractPriceinaccordancewiththefollowingschedule:(a)Adepositof10%oftheContractPriceshallbepaidbytheShipownertotheShipbuilderwithin[Number,e.g.,30]daysafterthedateofthisContract.(b)Theremaining90%shallbepaidbytheShipownertotheShipbuilderin[Number,e.g.,three]equalmonthlyinstallmentscommencingonthe[SpecifyDate]aftertheDeliveryDate,subjecttotheVesselbeingdeliveredandtherelevantclasscertificatebeingissued.(c)Eachinstallmentshallbedueandpayableonthe[SpecifyDate,e.g.,10th]dayofthemonthfollowingthemonthinwhichthecorrespondingworkwascompleted,ascertifiedbytheClassificationSociety.5.4Paymentshallbemadeby[SpecifyMethod,e.g.,banktransfer]tothebankaccountoftheShipbuilderspecifiedbelow:AccountName:[Shipbuilder'sBankAccountName]Bank:[Shipbuilder'sBankName]Address:[Shipbuilder'sBankAddress]BIC/SWIFTCode:[Shipbuilder'sBIC/SWIFTCode]IBAN:[Shipbuilder'sIBAN,ifapplicable]5.5TheShipbuildershallprovideacertificateofpaymentforeachinstallmentreceived.IftheShipownerfailstomakeapaymentwhendue,theShipownershallpayinterestontheoverdueamountatarateof[SpecifyRate,e.g.,LIBORplus[Number]%]perannum,calculateddailyfromtheduedateuntilthedateofpayment.6.Completion6.1CompletionshallbedeemedtohavebeenachievedwhentheVesselhassuccessfullycompletedtheSeaTrialasdefinedhereinandtheShipbuilderhasobtainedtherelevantclasscertificatefortheVesselfromtheClassificationSociety.6.2TheSeaTrialshallbeconductedattheDeliveryPointunderthesupervisionoftheClassificationSocietyandtheShipowner'srepresentatives.TheVesselshallsatisfytheperformancestandardsspecifiedinScheduleA.TheSeaTrialreportissuedbytheClassificationSocietyshallbefinalandbindingforthepurposeofdeterminingCompletion.6.3TheShipbuildershallberesponsibleforallcostsassociatedwiththeSeaTrial.TheShipownershallbearthecostsofitsrepresentativesparticipatingintheSeaTrial.7.Acceptance7.1UponCompletion,theShipbuildershallgivewrittennoticetotheShipowner.7.2TheShipownershallhaveaperiodof[Number,e.g.,60]daysfromthedateoftheShipbuilder'snoticetoinspecttheVesselandperformnecessarytrialrunsatitsownexpense.TheShipownershallnotifytheShipbuilderinwritingwithin[Number,e.g.,30]daysoftheendofthisinspectionperiodeitheracceptingtheVesselorspecifying,indetail,anydefectsornon-conformitiesthatmustberectified.7.3IftheShipownerdoesnotnotifytheShipbuilderofdefectswithintheperiodspecifiedinClause7.2,theVesselshallbedeemedaccepted.IftheShipownernotifiestheShipbuilderofdefects,theShipbuildershallrectifythedefectswithinareasonabletimeasagreedwiththeShipowner.IfthePartiescannotagreeontherectificationperiod,themattershallbesubmittedtotheArbitration.7.4AcceptanceoftheVesseldoesnotreleasetheShipbuilderfromitswarrantiesorliabilitiesunderthisContract.8.Warranties8.1TheShipbuilderwarrantsthattheVesselshallbeconstructedinaccordancewiththeSpecificationsandallapplicablelawsandregulations.8.2TheShipbuilderwarrantsthattheVesselandallitsequipmentshallbefreefromdefectsinmaterialsandworkmanshipfortheperiodsspecifiedinScheduleA:(a)[Number,e.g.,7]yearsforthehullandsuperstructure;and(b)fortheequipment,theperiodprovidedbytherespectivemanufacturers,commencingfromthedateofdeliveryoftheequipmenttotheShipbuilderandsubjecttotheShipbuilder'scompliancewithallinstructionsandmaintenancerequirements.8.3Thewarrantiesshallbeexclusiveandinlieuofallotherwarranties,expressorimplied,includingwarrantiesofmerchantabilityandfitnessforaparticularpurpose.8.4TheShipbuildershallbeliableforanylossordamagecausedbymaterialdefectsintheVesseloritsequipmentduringthewarrantyperiod.TheShipbuilder'sliabilityshallbelimitedtothecostofrectificationorreplacementofthedefectiveparts.8.5TheShipownershallpromptlynotifytheShipbuilderinwritingofanydefectsdiscoveredwithinthewarrantyperiod.Failuretogivesuchnotificationshallnotaffectthevalidityofthewarranty.9.ForceMajeure9.1NeitherPartyshallbeliableforanyfailuretoperformitsobligationsunderthisContractifsuchfailureiscausedbyaForceMajeureEvent.9.2"ForceMajeureEvent"meansanyeventbeyondthereasonablecontroloftheaffectedParty,includingbutnotlimitedtoactsofGod,war,terrorism,riots,strikes,civilcommotion,governmentactionorregulation,fire,flood,storm,earthquake,epidemic,orothersimilarevents.9.3ThePartyaffectedbyaForceMajeureEventshallpromptlynotifytheotherPartyinwritingoftheeventandtakeallreasonablemeasurestomitigatetheeffectsthereof.9.4TheaffectedPartyshallnotbeliableforanydelaysorfailuresinperformancecausedbytheForceMajeureEvent,butshallberequiredtocontinueitseffortstoperformitsobligationsoncetheeventhasceased.ThedurationoftheForceMajeureEventshallbedeterminedbytheaffectedPartyinitssolediscretion.10.IntellectualProperty10.1Alldesigns,drawings,specifications,andothertechnicaldocumentscreatedbytheShipbuilderinconnectionwiththeconstructionoftheVesselshallremainthepropertyoftheShipbuilder.10.2TheShipownershallbegrantedanon-exclusive,royalty-freelicensetousesuchdocumentssolelyforthepurposeofoperatingtheVesselconstructedunderthisContract.10.3TheShipbuildershallnotuseanyproprietaryinformationorintellectualpropertyoftheShipownerexceptasnecessaryfortheperformanceofthisContract.11.Confidentiality11.1EachPartyshallkeepconfidentialallinformationdisclosedbytheotherPartyinconnectionwiththisContract,includingbutnotlimitedtotheSpecifications,costdata,andbusinessinformation.11.2Theconfidentialityobligationshallnotapplytoinformationthat:(a)isorbecomespubliclyknownwithoutbreachofthisContract;(b)isalreadyinthepossessionofthereceivingPartyatthetimeofdisclosure;(c)isobtainedfromathirdpartywithoutbreachofsuchthirdparty'sobligationsofconfidentiality;or(d)isrequiredbylaworcourtordertobedisclosed.11.3ThereceivingPartyshallnotdiscloseanyconfidentialinformationtoanythirdpartywithoutthepriorwrittenconsentofthedisclosingParty,exceptasnecessaryinconnectionwiththeperformanceofthisContractorasrequiredbylaw.11.4ThisconfidentialityobligationshallsurvivetheterminationorexpirationofthisContractforaperiodof[Number,e.g.,five]yearsaftertheterminationorexpirationdate.12.Liability12.1Tothefullestextentpermittedbylaw,eachPartyshallbeliabletotheotherPartyonlyfordirectdamagesresultingfromitsbreachofthisContract.EachPartyshallnotbeliableforindirect,consequential,special,orpunitivedamages.12.2ThetotalliabilityofeachPartyunderthisContractshallnotexceedtheContractPrice.13.Notices13.1Allnotices,requests,demands,andothercommunicationsrequiredorpermittedunderthisContractshallbeinwritingandshallbedeemedtohavebeendulygiven:(a)whendeliveredpersonally;or(b)onebusinessdayafterdepositwithareputableovernightcourierservice;or(c)threebusinessdaysaftermailingbyregisteredorcertifiedmail,returnreceiptrequested,postageprepaid.13.2NoticesshallbeaddressedtothePartiesattheaddressessetforthbeloworatsuchotheraddressasaPartymaydesignatebynoticetotheotherParty.14.Amendments14.1NoamendmentormodificationofthisContractshallbevalidunlessitisinwritingandsignedbyauthorizedrepresentativesofbothParties.15.Assignment15.1NeitherPartymayassignanyofitsrightsorobligationsunderthisContract,inwholeorinpart,withoutthepriorwrittenconsentoftheotherParty.Anyattemptedassignmentwithoutsuchconsentshallbenullandvoid.16.Severability16.1IfanyprovisionofthisContractisheldbyacourtofcompetentjurisdictiontobeinvalid,illegal,orunenforceable,theremainingprovisionsofthisContractshallremaininfullforceandeffect.17.EntireAgreement17.1ThisContractconstitutestheentireagreementbetweenthePartieswithrespecttothesubjectmatterhereofandsupersedesallprioragreements,negotiations,andunderstandings,whetherwrittenororal,relatingtothesubjectmatterofthisContract.18.GoverningLawandArbitration18.1ThisContractshallbegovernedbyandconstruedinaccordancewiththelawsof[SpecifyJurisdiction].18.2Anydispute,controversy,orclaimarisingoutoforinconnectionwiththisContract,includinganyquestionregardingitsexistence,validity,ortermination,shallbereferredtoandfinallyresolvedbyArbitrationinaccordancewiththeRulesof[SpecifyArbitrationInstitution]asinforc
溫馨提示
- 1. 本站所有資源如無特殊說明,都需要本地電腦安裝OFFICE2007和PDF閱讀器。圖紙軟件為CAD,CAXA,PROE,UG,SolidWorks等.壓縮文件請下載最新的WinRAR軟件解壓。
- 2. 本站的文檔不包含任何第三方提供的附件圖紙等,如果需要附件,請聯(lián)系上傳者。文件的所有權(quán)益歸上傳用戶所有。
- 3. 本站RAR壓縮包中若帶圖紙,網(wǎng)頁內(nèi)容里面會有圖紙預(yù)覽,若沒有圖紙預(yù)覽就沒有圖紙。
- 4. 未經(jīng)權(quán)益所有人同意不得將文件中的內(nèi)容挪作商業(yè)或盈利用途。
- 5. 人人文庫網(wǎng)僅提供信息存儲空間,僅對用戶上傳內(nèi)容的表現(xiàn)方式做保護處理,對用戶上傳分享的文檔內(nèi)容本身不做任何修改或編輯,并不能對任何下載內(nèi)容負責。
- 6. 下載文件中如有侵權(quán)或不適當內(nèi)容,請與我們聯(lián)系,我們立即糾正。
- 7. 本站不保證下載資源的準確性、安全性和完整性, 同時也不承擔用戶因使用這些下載資源對自己和他人造成任何形式的傷害或損失。
最新文檔
- 2025年麗江文化旅游學(xué)院招聘140名教師備考題庫參考答案詳解
- 棗莊技師學(xué)院2025年第二批公開招聘備案制工作人員備考題庫參考答案詳解
- 2025年中國疾病預(yù)防控制中心環(huán)境與健康相關(guān)產(chǎn)品安全所科研項目財務(wù)管理人員招聘備考題庫附答案詳解
- 江門市暨南大學(xué)附屬江門中醫(yī)院(江門市五邑中醫(yī)院)2026年人才招聘45人備考題庫及一套參考答案詳解
- 2025年湖州莫干山國有資本控股集團有限公司招聘工作人員備考題庫含答案詳解
- 2025年中國地質(zhì)調(diào)查局烏魯木齊自然資源綜合調(diào)查中心公開招聘工作人員12人備考題庫(第五批)及完整答案詳解1套
- 2025年重慶醫(yī)科大學(xué)附屬康復(fù)醫(yī)院門診辦導(dǎo)醫(yī)招聘備考題庫及一套完整答案詳解
- 川崎病護理費試卷及答案
- 2025年貴陽云巖經(jīng)開產(chǎn)業(yè)發(fā)展集團有限公司社會公開招聘8人備考題庫及參考答案詳解1套
- 2025年勞務(wù)派遣人員招聘(派遣至浙江大學(xué)物理學(xué)院)備考題庫完整答案詳解
- 高級生物化學(xué)知識要點詳解
- GB/T 45683-2025產(chǎn)品幾何技術(shù)規(guī)范(GPS)幾何公差一般幾何規(guī)范和一般尺寸規(guī)范
- 可靠性測試標準試題及答案
- 入股境外合同協(xié)議書
- 一般將來時復(fù)習(xí)教案
- 2024-2025學(xué)年成都市青羊區(qū)九年級上期末(一診)英語試題(含答案和音頻)
- 2025年江蘇蘇豪控股集團招聘筆試參考題庫含答案解析
- 2024年氯化芐基三甲銨項目可行性研究報告
- 浙江財經(jīng)大學(xué)《中級計量經(jīng)濟學(xué)》2021-2022學(xué)年第一學(xué)期期末試卷
- 企業(yè)公司2025年工作總結(jié)暨2025年工作計劃
- 【MOOC】模擬電子技術(shù)基礎(chǔ)-華中科技大學(xué) 中國大學(xué)慕課MOOC答案
評論
0/150
提交評論