住宅小區(qū)消防噴淋系統(tǒng)升級合同（2026年）residentialcommunityfiresprinklersystemupgradecontract(2026)thiscontractisenteredintoandmadeeffectiveasof[signaturedate],[signatureyear],at[signaturelocation],between[contractor'sfullname],hereinafterreferredtoas"partya"(thecontractor),and[client'sfullname],hereinafterreferredtoas"partyb"(theclient).1.projectoverviewandscopeofwork1.1thiscontractreferstothe"residentialcommunityfiresprinklersystemupgradeproject"locatedat[projectaddress].1.2thescopeofworkfortheupgradeprojectshallinclude,butnotbelimitedto:1.2.1siteinvestigationandassessment:conductinginspectionandassessmentontheexistingfiresprinklersystemtodeterminethenecessityandspecificplanfortheupgrade.1.2.2designandproposal:formulatingadetailedupgradedesignplanbasedontheassessmentresultsandnationalandlocalfiresafetycoderequirements,whichmayinvolvedrawingpreparation,recommendationofmaterialtypes,specifications,andtechnicalparameters.1.2.3equipmentprocurement:clearlyspecifyingthemodels,specifications,quantities,technicalparameters,andqualitystandardsoftheneworreplacedfiresprinklerheads,pipes,valves,firepumps,alarmcontrollers,pressureswitches,flowswitches,andotherequipmentrequiredfortheproject.allequipmentshallcomplywithnationalandlocalfirecodesandregulationsandpossessrelevantcertifications(e.g.,ccccertification,fireproductcertification).1.2.4constructionandinstallation:detailingspecificconstructionproceduresincludingpipelaying,sprinklerheadinstallation,valvereplacement,firepumproomequipmentinstallationandcommissioning,systemwiringlaying,connectionwiththeexistingfirecontrolsystem,pressuretesting,flushing,etc.1.2.5systemcommissioningandtesting:aftercompletionofinstallation,conductingsystemcommissioningwithwatertoensureallcomponentsoperatenormally,pressuremeetsdesignrequirements,andfunctionssuchasalarmandlinkagecomplywithcodes.1.2.6documentationpreparationandhandover:providingcomplete竣工drawings,equipmentcertificatesofconformity,inspectionreports,acceptancedocuments,andothertechnicaldata.1.2.7training:providingbasictrainingforthepropertymanagementoruser'smaintenancepersonnelonsystemoperationanddailymaintenance.1.3thetechnicalstandardsandspecificationstobefollowedfortheprojectshallcomplywithnational,industry,andlocalfiretechnicalstandards,codes,andregulations,suchas"codefordesignofwatersupplyandfirehydrantsystem"(gb50974)and"codeforconstructionandacceptanceofautomaticsprinklersystem"(gb50261).2.contractdocumentsthefollowingdocuments,whetherwrittenororal,constituteanintegralpartofthiscontract:2.1thiscontractitself.2.2biddingdocuments(ifapplicable).2.3awardnotice.2.4letterofcontractaward.2.5appendicestothecontract,includingbillofquantities,technicalspecifications,designdrawings,equipmentlist,etc.2.6writteninstructionsorchangenoticesissuedbypartyb.2.7documentssubmittedbypartya,suchasprogressplans,self-inspectionreports,etc.3.contractpriceandpaymentterms3.1thecontractpriceshallbe[fixedsum/fixedunitprice/variableprice]basedon[providebasisforpricing].3.2thetotalcontractpriceis[amountinrmb].3.3thecurrencyshallbethechineseyuan(rmb).3.4paymenttermsshallbedetailedasfollows:3.4.1advancepayment:partybshallpayanadvancepaymentof[percentage]%ofthetotalcontractpricewithin[number]daysafterthecontractissigned.3.4.2progresspayments:paymentsshallbemadeaccordingtotheproject形象progressorcompletionofspecificworkitems.multiplepaymentsmaybescheduled,withthebasisandpercentageforeachpaymentclearlydefined.3.4.3acceptancepayment/qualityguaranteedeposit:aportionofthepaymentshallbemadeaftertheprojectisaccepted,oracertainpercentageshallberetainedasaqualityguaranteedeposit(typically5%-10%ofthetotalcontractprice).3.4.4returnofqualityguaranteedeposit:thequalityguaranteedepositshallbereturnedtopartyawithin[number]daysafterthequalityguaranteeperiodexpiresandnoissuesarefound.3.5partybshallpaytheamountsduetopartyaintothebankaccountprovidedbypartya.4.projectdurationandschedule4.1thescheduledstartdatefortheprojectis[date],andthescheduledcompletiondateis[date].4.2thetotalprojectdurationis[number]days/monthsfromthescheduledstartdate.4.3partyashallsubmitadetailedconstructionscheduletopartybforconfirmation.4.4delaysincompletion:thecontractshallstipulatethereasonsforwhichdelaysmayoccur(suchaspartya'sreasons,forcemajeure,designchanges,partyb'sreasons,etc.)andthecorrespondinghandlingmethods(suchasextensionofcontractduration,liquidateddamages,etc.).Delayscausedbypartya'sreasons(e.g.,failuretoprovideconstructionconditions,delayinconfirmingdrawingswithoutgoodreason)shallentitlepartybtorequestanextensionofcontractdurationandcompensationforcosts.5.rightsandobligationsofbothparties5.1rightsandobligationsofpartya:5.1.1providenecessaryconstructionsite,watersource,powersource,andotherconditions.5.1.2reviewtheconstructionorganizationplan,progressschedule,andotherdocumentssubmittedbypartyb.5.1.3paythecontractpriceinaccordancewiththeagreement.5.1.4organizeorparticipateintheprojectacceptance.5.1.5providerelevantdataoftheexistingfiresystem.5.1.6superviseprojectqualityandsafety.5.2rightsandobligationsofpartyb:5.2.1completetheprojectinaccordancewiththeagreedscope,standards,andschedule.5.2.2independentlybeartheresponsibilityforpersonnel,materials,equipment(unlessotherwisestipulatedinthecontractthatpartyashallprovide),constructiontools,etc.requiredforconstruction.5.2.3ensureconstructionqualityandsafetyproduction,complywiththemanagementregulationsofthecommunity.5.2.4cooperatewithinspectionsandacceptancebypartyaandrelevantauthorities.5.2.5beresponsibleforconstructionmanagementonsiteandcivilizedconstruction.5.2.6submitcompletiondocumentsandbearthecostsofinspectionapplications.5.2.7beartheresponsibilityfordelaysincontractdurationandcostscausedbyitsownreasons.6.qualityandacceptanceoftheproject6.1qualitystandards:theprojectqualitymustmeetthenationalandlocalfirecodesandregulationsandpassthefinalacceptancebythefiredepartment.6.2inspectionandself-inspection:partybshallconductself-inspectionandnotifypartyaorthesupervisorforinspectionatkeynodes.6.3acceptance:theprocedureforprojectacceptanceshallbestipulated,includingdocumentpreparation,on-siteinspection,andfinalacceptancebythefiredepartment.6.4handlingofqualityissues:thecontractshallstipulatetheresponsibilitiesandproceduresforhandlingqualityissuesthatariseduringthewarrantyperiod.7.safetymanagement7.1safetyresponsibilities:clarifytherespectivesafetyresponsibilitiesofbothpartiesduringtheconstructionprocess.partyb,astheconstructor,bearstheprimaryresponsibilityforon-siteconstructionsafetyandshallestablishasafetymanagementsystem,deploysafetypersonnel,andadoptsafetymeasures.7.2accidenthandling:thecontractshallstipulatetheproceduresandresponsibilitiesforhandlingsafetyaccidents.8.projectwarranty8.1warrantyperiod:thewarrantyperiodfortheprojectshallbefromthedateoffinalacceptanceto[number]years/months,calculatedfromthedatetheprojectisaccepted.criticalequipment(e.g.,firepumps)mayrequirealongerwarrantyperiod,whichshallcomplywiththe"fireprotectionlaw"andrelevantfirecodesandregulations.8.2warrantyscope:thewarrantyperiodcoversqualityissuesoftheprojectandthequalityofequipmentitselfwithinthescopeofthecontract.8.3warrantyresponsibilities:duringthewarrantyperiod,partybshallberesponsibleforfreerepairorreplacementifqualityissueswithinthewarrantyscopearise.9.changesandclaims9.1changeprocedure:thecontractshallstipulatetheprocedureforproposingandconfirmingchangestothedesignorprojectcontent.anychangesshallrequirewrittenconfirmationfrompartya,andthecontractpriceandcontractdurationshallbeadjustedaccordingly.9.2claims:thecontractshallspecifythatpartybhastherighttoclaimadditionalcostsordelaysincontractdurationcausedbyreasonsbeyondpartyb'scontrol(suchaspartya'sreasons,forcemajeure,etc.)andshallprovideevidencewithinthestipulatedtime.10.liabilityforbreachofcontract10.1liabilityforbreachofcontractbypartya:ifpartyafailstopayontime,failstoprovidenecessaryconditions,delaysacceptancewithoutgoodreason,etc.,itshallbearliabilityforbreachofcontract,whichmayincludepaymentofliquidateddamagesandcompensationforlosses.10.2liabilityforbreachofcontractbypartyb:ifpartybfailstomeetqualityrequirements,delayscompletion(notduetopartya'sreasons),failstofulfillsafetyresponsibilitiesleadingtoaccidents,etc.,itshallbearliabilityforbreachofcontract,whichmayincluderectification,paymentofliquidateddamages,andcompensationforlosses.11.forcemajeure11.1definition:forcemajeureshallrefertounforeseen,unavoidable,anduncontrollableobjectivecircumstances,suchasearthquakes,fires,wars,governmentactions,etc.11.2consequences:intheeventofforcemajeure,bothpartiesmaynegotiateforextensionofperformance,partialperformance,orterminationofthecontract.neitherpartyshallbearliabilityforbreachofcontract,butbothpartiesshallnotifyeachotherinatimelymannerandprovideproof.12.disputeresolution12.1disputeresolutionmethod:themethodforresolvingdisputesunderthiscontractshallbenegotiatedandmediatedinpriority.ifnegotiationandmediationfail,disputesshallbesubmittedto[arbitrationinstitution]forarbitration(shallspecifythearbitrationinstitution)orlitigation(shallspecifythecompetentcourt,typicallythecourtintheprojectlocationorthecontractsigninglocation).13.effectiveness,termination,andterminationofthecontract13.1effectivenessconditions:reiteratetheconditionsrequiredforthecontracttobecomeeffective.13.2termination:thecontractshallterminateundernormalcircumstancesuponcompletionandfulfillmentofthecontract,oruponterminationofthecontract.13.3terminationconditions:thecontractmaybeterminatedundercertaincircumstances(suchasseriousbreachofcontract,forcemajeure,mutualagreementofbothparties,etc.),andthelegalconsequencesofterm